Loren Data's SAM Daily™

FBO DAILY - FEDBIZOPPS ISSUE OF JUNE 14, 2017 FBO #5682
SOLICITATION NOTICE

J -- T.S. KENNEDY - Boiler Inspection & Testing - Attachment #1 - Attachment #2

Notice Date

6/12/2017
 

Notice Type

Combined Synopsis/Solicitation
 

NAICS

336611 — Ship Building and Repairing
 

Contracting Office

Department of Transportation, Maritime Administration (MARAD), SAR Acquisition, Office of Acquisition, MRG-7200, 7737 Hampton Boulevard, Building 4D, Room 211, Norfolk, Virginia, 23505, United States
 

ZIP Code

23505
 

Solicitation Number

6933A217Q00004
 

Archive Date

7/15/2017
 

Point of Contact

Monique R. Leake, Phone: (757) 322-5820
 

E-Mail Address

monique.leake@dot.gov
(monique.leake@dot.gov)
 

Small Business Set-Aside

Total Small Business
 

Description

Quote Price Sheet LP Turbine Report LP Strut Cracks MiTech Report Foster Wheeler Boiler Book Statement of Work This is a COMBINED SYNOPSIS/SOLICITATION for commercial items prepared in accordance with the information in FAR Subpart 12.6, as supplemented with the additional information included in this notice. This solicitation is advertised as a small business set-aside in accordance with FAR Subpart 13.5 – Test Program for Certain Commercial Items. This announcement constitutes the only solicitation; a written solicitation (SF-1449) will not be issued. PAPER COPIES OF THIS SOLICITATION WILL NOT BE AVAILABLE. This combined synopsis/solicitation SHALL be posted to FEDBIZOPPS ( https://www.fbo.gov/ ) The RFQ number is 6933A217Q00004. This solicitation documents and incorporates provisions and clauses in effect through FAC 2005-94, 2005-95 effective January 19, 2017. It is the responsibility of the contractor to be familiar with the applicable clauses and provisions. The FAR clauses may be accessed in full text at these addresses https://www.acquisition.gov/?q=browsefar. The full text of the Transportation Acquisition Regulations (TAR) (1252.) can be found at: http://www.dot.gov/ost/m60/tamtar/part1252.htm and the full text of the U.S. Maritime Administration Provisions and Clauses (MCL) can be found at: https://voa.marad.dot.gov/Solicitation_Awards/docs/mar-380/MARAD%20Clauses%20MCL%20for%20HTML.htm The applicable NAICS code is 336611 and this is a small business set-aside action. The U.S. Maritime Administration (MARAD), Norfolk, VA intends to award a firm fixed price purchase order with for T.S. KENNEDY for the following services: The U.S. Maritime Administration (MARAD), Norfolk, VA intends to award a firm fixed price purchase order for service and material to perform the a USCG required boiler inspection on the Training Ship KENNEDY located at the Massachusetts Maritime Academy, 101 Academy Drive, Buzzards Bay, MA 02532, in accordance with the Statement of Work (Attachment 1). The requested period of performance is June 10, 2017 through August 03, 2017. SITE VISIT A site visit will be conducted onboard the T.S. KENNEDY at 9:00 a.m. Eastern Standard Time on Tuesday, June 20, 2017, at 101 Academy Drive, Buzzards Bay, MA 02532. POC: Jeff Brown, Marine Surveyor, USDOT- Maritime Administration (MARAD), Division of Atlantic Operations-New England Office; e-mail: Jeffrey.H.Brown@dot.gov. All potential offerors intending to submit an offer should plan to attend site visit. In order to make the site visit as productive as possible, offerors are also requested to submit any questions from the review of the solicitation package or as a result of site visit should be submitted in writing (email) to the Contracting Officer Monique.Leake@dot.gov No Later Than 12:00 p.m. Eastern Standard Time on June 22, 2017 with solicitation number 6933A217Q00004 in the subject line. Responses to questions will be issued by amendment to the solicitation package. Failure of a prospective offeror to submit any questions or to attend the site visit will be construed to mean that the offeror fully understands all requirements of the solicitation. Prospective offerors are advised that the site visit will be held solely to allow offerors an opportunity to gain the best possible understanding of the working environment and specific work items to be addressed under contract in order that they may prepare an accurate and complete price quote. All prospective offerors are advised that at the conclusion of the site visit, unless this solicitation is amended in writing, it will remain unchanged and, that if an Amendment is issued, normal procedures relating to the acknowledgment and receipt of any such amendment shall be applicable. Contract Clauses 52.212-4 Contract Terms and Conditions - Commercial Items. (JAN 2017) (a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights— (1) Within a reasonable time after the defect was discovered or should have been discovered; and (2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item. (b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act ( 31 U.S.C. 3727 ). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract. (c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties. (d) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract. (e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference. (f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence. (g) Invoice. (1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include— (i) Name and address of the Contractor; (ii) Invoice date and number; (iii) Contract number, line item number and, if applicable, the order number; (iv) Description, quantity, unit of measure, unit price and extended price of the items delivered; (v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading; (vi) Terms of any discount for prompt payment offered; (vii) Name and address of official to whom payment is to be sent; (viii) Name, title, and phone number of person to notify in event of defective invoice; and (ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract. (x) Electronic funds transfer (EFT) banking information. (A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract. (B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer—System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer—Other Than System for Award Management), or applicable agency procedures. (C) EFT banking information is not required if the Government waived the requirement to pay by EFT. (2) Invoices will be handled in accordance with the Prompt Payment Act ( 31 U.S.C. 3903 ) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR Part 1315. (h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings. (i) Payment.— (1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract. (2) Prompt payment. The Government will make payment in accordance with the Prompt Payment Act ( 31 U.S.C. 3903 ) and prompt payment regulations at 5 CFR Part 1315. (3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5 ( b) for the appropriate EFT clause. (4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made. (5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall— (i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the— (A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment); (B) Affected contract number and delivery order number, if applicable; (C) Affected line item or subline item, if applicable; and (D) Contractor point of contact. (ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer. (6) Interest. (i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided i n 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid. (ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract. (iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if— (A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days; (B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or (C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2 ). (iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment. (v) Amounts shall be due at the earliest of the following dates: (A) The date fixed under this contract. (B) The date of the first written demand for payment, including any demand for payment resulting from a default termination. (vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on— (A) The date on which the designated office receives payment from the Contractor; (B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or (C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor. (vii) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract. (j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon: (1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or (2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination. (k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties. (l) Termination for the Government’s convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor’s records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided. (m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience. (n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession. (o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract. (p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items. (q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract. (r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. chapter 37, Contract Work Hours and Safety Standards; 41 U.S.C. chapter 87, Kickbacks; 41 U.S.C. 4712 and 10 U.S.C. 2409 relating to whistleblower protections; 49 U.S.C. 40118, Fly American; and 41 U.S.C. chapter 21 relating to procurement integrity. (s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order: (1) The schedule of supplies/services. (2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause; (3) The clause at 52.212-5. (4) Addenda to this solicitation or contract, including any license agreements for computer software. (5) Solicitation provisions if this is a solicitation. (6) Other paragraphs of this clause. (7) The Standard Form 1449. (8) Other documents, exhibits, and attachments. (9) The specification. (t) System for Award Management (SAM). (1) Unless exempted by an addendum to this contract, the Contractor is responsible during performance and through final payment of any contract for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government’s reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. (2)(i) If a Contractor has legally changed its business name, “doing business as” name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in FAR subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day’s written notification of its intention to (A) change the name in the SAM database; (B) comply with the requirements of subpart 42.12 ; and (C) agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide with the notification sufficient documentation to support the legally changed name. (ii) If the Contractor fails to comply with the requirements of paragraph (t)(2)(i) of this clause, or fails to perform the agreement at paragraph (t)(2)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the “Suspension of Payment” paragraph of the electronic funds transfer (EFT) clause of this contract. (3) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims (see subpart 32.8, Assignment of Claims). Assignees shall be separately registered in the SAM database. Information provided to the Contractor’s SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the “Suspension of payment” paragraph of the EFT clause of this contract. (4) Offerors and Contractors may obtain information on registration and annual confirmation requirements via SAM accessed through https://www.acquisition.gov. (u) Unauthorized Obligations (1) Except as stated in paragraph (u)(2) of this clause, when any supply or service acquired under this contract is subject to any End User License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern: (i) Any such clause is unenforceable against the Government. (ii) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an “I agree” click box or other comparable mechanism (e.g., “click-wrap” or “browse-wrap” agreements), execution does not bind the Government or any Government authorized end user to such clause. (iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement. (2) Paragraph (u)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures. (v) Incorporation by reference. The Contractor’s representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract. (End of clause) 52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders—Commercial Items. (JAN 2017) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (2) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015). (3) 52.233-3, Protest After Award (AUG 1996) ( 31 U.S.C. 3553 ). (4) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004)(Public Laws 108-77 and 108-78 ( 19 U.S.C. 3805 note ) ). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check √ as appropriate.] √ (1 ) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) ( 41 U.S.C. 4704 and 10 U.S.C. 2402 ). __ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) ( 41 U.S.C. 3509 ) ). __ (3 ) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.) √ (4 ) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. <img src="file:///C:/Users/MONIQU~1.LEA/AppData/Local/Temp/1/msohtmlclip1/01/clip_image002.gif" border="0" alt="" width="180" height="28" /> ). √ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C). __ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C). √ (8) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note). √ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313). __ (10) [Reserved]. __ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) ( 15 U.S.C. 657a ). __ (ii) Alternate I (Nov 2011) of 52.219-3. __ (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) ( 15 U.S.C. 657a ). __ (ii) Alternate I (JAN 2011) of 52.219-4. __ (13) [Reserved] √ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2011) ( 15 U.S.C. 644 ). __ (ii) Alternate I (Nov 2011). __ (iii) Alternate II (Nov 2011). __ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) ( 15 U.S.C. 644 ). __ (ii) Alternate I (Oct 1995) of 52.219-7. __ (iii) Alternate II (Mar 2004) of 52.219-7. √ (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) ( 15 U.S.C. 637(d)(2) and (3)). __ (17)(i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) ( 15 U.S.C. 637(d)(4) ). __ (ii) Alternate I (Nov 2016) of 52.219-9. __ (iii) Alternate II (Nov 2016) of 52.219-9. __ (iv) Alternate III (Nov 2016) of 52.219-9. __ (v) Alternate IV (Nov 2016) of 52.219-9. __ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) ( 15 U.S.C. 644(r) ). √ (19) 52.219-14, Limitations on Subcontracting (Jan 2017) ( 15 U.S.C. 637(a)(14) ). __ (20) 52.219-16, Liquidated Damages—Subcon-tracting Plan (Jan 1999) ( 15 U.S.C. 637(d)(4)(F)(i) ). __ (21 ) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) ( 15 U.S.C. 657 f ). √ (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) ( 15 U.S.C. 632(a)(2) ). _ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Dec 2015) ( 15 U.S.C. 637(m) ). __ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) ( 15 U.S.C. 637(m) ). √ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755). √ (26) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126). √ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). √ (28) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246). √ (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015)( 38 U.S.C. 4212 ). √ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) ( 29 U.S.C. 793 ). √ (31) 52.222-37, Employment Reports on Veterans (FEB 2016) (38 U.S.C. 4212). √ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). <img src="file:///C:/Users/MONIQU~1.LEA/AppData/Local/Temp/1/msohtmlclip1/01/clip_image004.gif" border="0" alt="" width="121" height="34" />, Combating Trafficking in Persons (Mar 2015) ( 22 U.S.C. chapter 78 and E.O. __ (ii) Alternate I (Mar 2015) of 52.222-50 ( 22 U.S.C. chapter 78 and E.O. 13627). √ (34) 52.222-54, Employment Eligibility Verification (OCT 2015). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803. ) __ (35) 52.222-59, Compliance with Labor Laws (Executive Order 13673) (OCT 2016). (Applies at $50 million for solicitations and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for solicitations and resultant contracts issued after April 24, 2017). Note to paragraph (b)(35) : By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, GSA, DoD and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. __ (36) 52.222-60, Paycheck Transparency (Executive Order 13673) (OCT 2016). √ (37)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) ( 42 U.S.C. 6962(c)(3)(A)(ii) ). (Not applicable to the acquisition of commercially available off-the-shelf items.) __ (ii) Alternate I (May 2008) o f 52.223-9 ( 42 U.S.C. 6962(i)(2)(C) ). (Not applicable to the acquisition of commercially available off-the-shelf items.) √ (38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (JUN 2016) (E.O. 13693). __ (39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (JUN 2016) (E.O. 13693). __ (40)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (JUN 2014) (E.O.s 13423 and 13514). __ (ii) Alternate I (Oct 2015) of 52.223-13. __ (41)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (JUN 2014) (E.O.s 13423 and 13514). __ (ii) Alternate I (Jun 2014) of 52.223-14. __ (42) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) ( 42 U.S.C. 8259b ). <img src="file:///C:/Users/MONIQU~1.LEA/AppData/Local/Temp/1/msohtmlclip1/01/clip_image006.gif" border="0" alt="" width="123" height="28" />, Acquisition of EPEAT®-Registered Personal Computer Products (OCT 2015) (E.O.s __ (ii) Alternate I (Jun 2014) of 52.223-16. √ (44) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (AUG 2011) (E.O. 13513). __ (45) 52.223-20, Aerosols (JUN 2016) (E.O. 13693). __ (46) 52.223-21, Foams (JUN 2016) (E.O. 13693). __ (47)(i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a). __ (ii) Alternate I (JAN 2017) of 52.224-3. __ (48) 52.225-1, Buy American—Supplies (May 2014) ( 41 U.S.C. chapter 83 ). __ (49)(i) 52.225-3, Buy American—Free Trade Agreements—Israeli Trade Act (May 2014) ( 41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43. __ (ii) Alternate I (May 2014) of 52.225-3. __ (iii) Alternate II (May 2014) of 52.225-3. __ (iv) Alternate III (May 2014) of 52.225-3. __ (50) 52.225-5, Trade Agreements (OCT 2016) ( 19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). √ (51) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). __ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). __ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) ( 42 U.S.C. 5150 ). __ (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) ( 42 U.S.C. 5150 ). __ (55) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) ( 41 U.S.C. 4505, 10 U.S.C. 2307(f) ). __ (56) 52.232-30, Installment Payments for Commercial Items (Jan 2017) ( 41 U.S.C. 4505, 10 U.S.C. 2307(f) ). √ (57 ) 52.232-33, Payment by Electronic Funds Transfer—System for Award Management (Jul 2013) ( 31 U.S.C. 3332 ). __ (58) 52.232-34, Payment by Electronic Funds Transfer—Other than System for Award Management (Jul 2013) ( 31 U.S.C. 3332 ). __ (59) 52.232-36, Payment by Third Party (May 2014) ( 31 U.S.C. 3332 ). __ (60) 52.239-1, Privacy or Security Safeguards (Aug 1996) ( 5 U.S.C. 552a ). __ (61) 52.242-5, Payments to Small Business Subcontractors (JAN 2017)(15 U.S.C. 637(d)(12)). __ (62)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) ( 46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631 ). __ (ii) Alternate I (Apr 2003) of 52.247-64. (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] __ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014)(E.O. 13495). √ (2) 52.222-41, Service Contract Labor Standards (May 2014) ( 41 U.S.C. chapter 67 ). √ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) ( 29 U.S.C. 206 and 41 U.S.C. chapter 67 ). In compliance with the Service Contract Labor Standards statute and the regulations of the Secretary of Labor (29 CFR part 4), this clause identifies the classes of service employees expected to be employed under the contract and states the wages and fringe benefits payable to each if they were employed by the contracting agency subject to the provisions of 5 U.S.C. 5341 or 5332. This Statement is for Information Only: Employee Class Monetary Wage – Fringe Benefits Electrician, Maintenance $32.50 Welder, Maintenance $32.50 Machinery Maintenance Mechanic $32.50 Pipefitter, Mechanic $32.50 Laborer $19.50 __ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (May 2014) ( 29 U.S.C. 206 and 41 U.S.C. chapter 67 ). √ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards—Price Adjustment (May 2014) ( 29 U.S.C. 206 and 41 U.S.C. chapter 67 ). __ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment—Requirements (May 2014) ( 41 U.S.C. chapter 67 ). __ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services—Requirements (May 2014) ( 41 U.S.C. chapter 67 ). √ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015). __ (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706). __ (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) ( 42 U.S.C. 1792 ). __ (11) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) ( 31 U.S.C. 5112(p)(1) ). (d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records—Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FA R subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (e)(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause— (i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) ( 41 U.S.C. 3509 ). (ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (iii) 52.219-8, Utilization of Small Business Concerns (Nov 2016) ( 15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (iv) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph (l) of FAR clause 52.222-17. (v) 52.222-21, Prohibition of Segregated Facilities (Apr 2015) (vi) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246). (vii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) ( 38 U.S.C. 4212 ). (viii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) ( 29 U.S.C. 793 ). (ix) 52.222-37, Employment Reports on Veterans (Feb 2016) ( 38 U.S.C. 4212 ) (x) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (xi) 52.222-41, Service Contract Labor Standards (May 2014) ( 41 U.S.C. chapter 67 ). (xii) 52.222-50, Combating Trafficking in Persons (Mar 2015) ( 22 U.S.C. chapter 78 a nd E.O 13627). Alternate I (Mar 2015) of 52.222-50 ( 22 U.S.C. chapter 78 and E.O 13627 ). (xiii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) ( 41 U.S.C. chapter 67 ). (xiv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) ( 41 U.S.C. chapter 67 ). (xv) 52.222-54, Employment Eligibility Verification (OCT 2015) (E.O. 12989). (xvi) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015). (xvii) 52.222-59, Compliance with Labor Laws (Executive Order 13673) (OCT 2016) (Applies at $50 million for solicitations and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for solicitations and resultant contracts issued after April 24, 2017). Note to paragraph (e)(1)(xvii) : By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, GSA, DoD and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. (xviii) 52.222-60, Paycheck Transparency (Executive Order 13673) (OCT 2016)). (xix) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706). (xx)(A) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a). (B) Alternate I (JAN 2017) of 52.224-3. (xxi) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). (xxii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) ( 42 U.S.C. 1792 ). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. (xxiii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) ( 46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631 ). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. (2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations. (End of clause) 52.252-2 Clauses Incorporated by Reference. (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov/?q=/browse/far/52 (End of clause) MCL.G-3 Invoice Submission Instructions The Contractor may submit invoices in either electronic or paper format. Electronic submission is preferred. (1) Electronic invoices shall be addressed to MARADInvoices@faa.gov. Electronic invoices shall conform to the following criteria, or be subject to rejection: a. Invoice and supporting documentation shall be in Adobe Acrobat (pdf) format. b. The e-mail subject shall include the contract/purchase order number and invoice number. c. The transmitting e-mail shall include the following information: Name of the Contractor; Invoice date and number; Invoice amount; Contract number and, if applicable, the order or modification number; Terms of any discount for prompt payment offered; Payment instructions (i.e., financial institution, ABA routing #, account #) (2) Paper invoices shall be submitted to one of the following addresses. Multiple copies are not required. MARAD A/P Invoices Branch AMZ-160 PO Box 25710 Oklahoma City, OK 73125 If a street address is required for delivery (i.e., Federal Express), the following address may be used in lieu of the post office box: MARAD A/P Invoices Branch AMZ-160 6500 S MacArthur Blvd. Oklahoma City, OK 73169 MCL.G-4 Applicable Service Contract Wage Determination The Service Contact Act wage determination applicable to this requirement is Wage Determination No. 15-4045, Revision No. 02 dated 01/03/2017, Massachusetts. The WD can be viewed using the following link: https://www.wdol.gov/wdol/scafiles/std/15-4045.txt?v=2 MCL.H-2 Supplemental Work Requests (a) In the complex world of ship repairs, supplemental work often emerges as a result of test, inspection, or discovery of unknown or otherwise differing conditions. The extent and nature of such supplemental work can neither be identified in bid or proposal specifications, and both parties recognize the possibility that such work may arise. Notwithstanding the possibility of the identification of such work, MARAD does not guarantee the award of any supplemental work during contract performance. (b) Although MARAD shall be under no obligation to award supplemental work during contract performance, MARAD has provided an estimate for labor (in labor hours) and material (in dollars) for such work in the Schedule (Section B of the solicitation under applicable supplemental work contract line item numbers (CLIN or CLINs)). The offeror shall specify an hourly composite billing rate in its bid or proposal for supplemental work labor. The composite labor-billing rate shall be the rate applicable to labor for all supplemental work that MARAD orders under the applicable supplemental CLIN of the resulting contract. Any supplies or subcontracts required to complete supplemental work will be charged as a direct cost reimbursable under the applicable supplemental work CLIN; additional indirect charges for materials and subcontracts will not be allowed. (c) During the performance of the contract, when conditions indicate a need for supplemental work, the Contracting Officer's Representative (COR) is empowered to provide technical direction, negotiate the amount of labor and material, and authorize the contractor to perform supplemental work through the issuance of a written authorization. The COR will issue authorizations for supplemental work in accordance with the following: (1) When conditions make supplemental work appropriate, the COR shall submit to the contractor a supplemental work request that identifies the work to be accomplished. (2) The Contractor shall promptly review each supplemental work request upon receipt and shall, within seventy-two (72) hours of issuance, or sooner, as specified by the COR, provide the COR with a proposed price for the supplemental work. Price proposals for all supplemental work must be broken down by labor hours, materials, and subcontracts and allocated to the applicable supplemental work CLIN as appropriate. The contractor shall price the supplemental work to be performed in accordance with the composite labor rate bid or proposed under the supplemental work CLIN in the contract. If necessary, the Contractor shall submit prices for subcontractors, which will be negotiated and treated as direct materials. Once the COR and contractor agree on the technical direction and price to accomplish the supplemental work, the contractor and COR shall sign the authorization for supplemental work, which shall be final and binding on the contractor and MARAD. Subject to paragraphs (c.)(3.) through (c.)(6.), if urgent circumstances do not permit waiting for a written authorization, the parties may orally agree and follow up with written confirmation. (3) Notwithstanding the preceding, the COR shall not authorize and the contractor shall not accept individual supplemental work authorizations from the COR in excess of the price ceiling established by the Contracting Officer pursuant to paragraph (d.)(10.). In addition, the COR shall not authorize and the contractor shall not accept a supplemental work authorization from the COR that, when combined with all previously authorized supplemental work under the contract, exceeds the amount of labor hours and materials specified in the applicable supplemental work CLINs. (4) If the contractor requests an adjustment to the contract completion date in its proposal for the supplemental work, the COR must refer the issue to the Contracting Officer for resolution, which could include modifying the performance period of the contract. All supplemental work must be accomplished within the contract performance period. The COR shall not authorize and the contractor shall not accept supplemental work authorizations from the COR that cannot be completed within the contract performance period. (5) If the COR and contractor cannot agree upon the price, the time required, or any other term of a supplemental work request, the matter shall be referred to the Contracting Officer who may resolve the issue in accordance with the procedures contained in the Changes clause incorporated in the contract. Specifically, the Contracting Officer shall have the option of (i) directing that the Contractor perform the work at a price and within a time period determined by the Contracting Officer to be reasonable, or (ii) withdrawing said supplemental work request. The Contractor's refusal to perform the work as directed by the Contracting Officer shall constitute an event of default under the default clauses of the contract. Disputed issues resulting from supplemental work unilaterally directed by the Contracting Officer may be handled under the disputes clause of the contract. (6) If the Contracting Officer directs the Contractor to perform the work at a price and within a time period determined by the Contracting Officer to be reasonable, the Contractor shall maintain and submit to MARAD on a daily basis, report sheets itemizing materials used, the costs and man hours of all labor (direct, indirect, and impact), production schedule activities affected by and/or related thereto, and charges for equipment, whether furnished by the Contractor, subcontractors or others. Material charges shall be substantiated by valid copies of materials and/or suppliers invoices. Such invoices shall be submitted with the daily report sheets or, if not available, as soon as reasonably practicable thereafter. Said daily reports shall also include an indication as to which specific schedule activity(ies) are affected by the order which are the subject of the daily report sheets. To the extent the contractor fails or refuses to submit the aforementioned daily report sheets on a daily basis, such failure or refusal shall constitute a basis for the Contracting Officer to suspend payment for work completed under the supplemental work until appropriate documentation required by the contract is provided. (d) The following rules apply to supplemental work authorizations: (1) The COR shall authorize supplemental-work only during the period of performance of the contract. (2) All authorizations for supplemental work are subject to the terms and conditions of the contract and must be within the scope of the contract. (3) If mailed, an authorization is considered "issued" when MARAD deposits the order in the mail. Authorizations may also be issued orally, or by written communications, that is hand-delivered or sent by facsimile or electronic transmission. Oral orders must be followed up by written confirmation as soon as practicable thereafter. (4) Unless otherwise explicitly noted in the authorization for supplemental work, all authorizations for supplemental work are firm fixed price. The agreed upon price shall cover all costs including, but not limited to, direct and indirect labor and material, overhead, delay, acceleration, and disruption caused by the supplemental work. Where the parties are unable to agree that an order establishes mutually agreeable terms, the parties shall note the specific differences that are not agreed upon in the text of the proposed work authorization and refer the matter to the Contracting Officer for resolution pursuant to paragraph (c.)(5.). (5) Unless the contractor otherwise explicitly notes in the supplemental work authorization, in consideration of the price of the order, the Contractor remises, releases, and forever discharges MARAD, its officers, agents, employees, and sureties from any and all civil claims and requests for equitable adjustment whatsoever, relating to, arising out of, or connected with said supplemental work authorization. Such release is full and final settlement of all claims and requests for equitable adjustment relating to, arising out of, or connected with the work authorization, as modified, including, but not limited to, all impact claims such as delay, acceleration, disruption, and cumulative effects of the instant and all previously issued supplemental work authorizations. The executed work authorization constitutes a complete and final adjustment of the price and the delivery schedule. (6) When MARAD requires supplies or services covered by the contract in an amount less than the total value of the contract, MARAD is not obligated to award supplemental work for the balance of the price bid or proposed for supplemental work. The Contractor is not obligated to honor additional supplemental work in excess of the estimated labor hours identified in the Schedule. This subparagraph does not affect or change the Contracting Officer's authority under the changes clause of the contract. (7) Except for limitations of labor hours estimated in the Schedule, there is no limit to the number of supplemental work authorizations that may be issued. MARAD may issue supplemental work authorizations requiring delivery or performance in multiple locations, if the contract contemplates multiple locations. (8) In the event a supplemental work authorization covers a series of related procedures, the Contracting Officer may request the Contractor to furnish separate prices for each item of the work. (9) If not otherwise provided, the Contracting Officer may request at any time during performance of supplemental work a list of subcontractors performing work covered by the supplemental work, the dollar value of the respective subcontracts, and a description of the subcontracted work and the contractor shall promptly provide the requested information. (10)The COR shall not issue and the contractor shall not accept supplemental work authorizations from the COR that exceeds (Contracting Officer fills in amount up to $5000.) MCL.H-3 Indemnity and Insurance The Contractor shall indemnify and save and keep harmless the Government against any or all loss, cost, damage, claim, expense or liability whatsoever because of accident or injury to persons or property of others occurring in connection with the operations under this contract. The Contractor shall secure, pay the premiums for and keep in force until the expiration of this contract, and any renewal thereof, adequate insurance. Such insurance to specifically include liability assumed by the Contractor under this contract. Each policy of insurance shall contain an endorsement that any cancellation or material change in the coverage adversely affecting the Government's interest shall not be effective unless the insurer or the Contractor gives written notice of cancellation or change as required to the Contracting Officer. When the coverage is provided by self-insurance, the Contractor shall not change or decrease the coverage without the Administrative Contracting Officer's prior approval. A certificate of each policy of insurance shall be furnished to the Contracting Officer within ten (10) days after notice of award certifying, among other things, that the policy contains the aforesaid endorsement. The insurance companies providing the above insurance shall be satisfactory to the Government. Notices of policy changes shall be furnished to the Contracting Officer. The contractor shall provide at the Contractor's expense, within five days of request from the MARAD contracting officer, a copy of all original insurance policies. These may be sent by mail or facsimile machine. MCL.H-4 Indemnity and Insurance (Additional) (a) INDEMNITY (1) The Contractor shall exercise reasonable care and use its best efforts to prevent accidents, injury or damage to all employees, persons and property in and about the work, and to the vessel or portion thereof upon which work is done. (2) Except as provided elsewhere in this contract, including any guarantee clause, the MARAD assumes the risk of physical loss or damage to any part of the vessel, its machinery, equipment, stores, and other property including cargo if owned by the Government except to the extent that such loss or damage is caused by the negligence, fault, error, act or omission of the Contractor, its subcontractors, agents, or employees. The burden of proving freedom from fault shall be borne by the Contractor. Unless the loss or damage was caused by the willful misconduct of the Contractor, its executive officers, or superintendents the Contractor's liability under this Contract shall not exceed total damage to the ship or ships including total loss up to $1,000,000 per accident or occurrence per vessel, and shall not exceed in the aggregate per accident or occurrence the sum of total damage to the ship or ships including total loss up to $1,000,000 multiplied by the number of MARAD's vessels in the care, custody or control of the Contractor at the location and at the time of the accident or occurrence giving to the loss or damage. (3) As to third parties, including, but not limited to, agents, employees or servants of the Contractor, or any subcontractor, the Contractor will defend, indemnify and hold harmless the Government, the vessel, its owners and charterers, from all claims, actions, suits, costs, demands and expense of all descriptions arising out of disease, illness, personal injury, death or property damage to any third party in any way related to or arising out of the performance of work under this contract except to the extent caused by the fault, error, act or omission, or negligence of the Government, its agencies or employees. The burden of proving fault of the Government, its agencies or employees shall be borne by the Contractor. (4) As to loss and damage which are the responsibility of the Government, the Government shall be subrogated to any claim, demand, or course of action against third parties which exists in favor of the Contractor, and the Contractor shall, if required, execute a formal assignment or transfer of such claim, demand, or course of action, and shall aid in securing information, evidence, obtaining of witnesses, and cooperate with MARAD in all matters MARAD may deem necessary in defense of any claim, or suit or appeal from any judgment or in effecting indemnity, provided, further, that nothing contained in this paragraph shall create or give rise to any right, privilege or power in any person except the Contractor, nor shall any person (except the Contractor) be or become entitled thereby to proceed directly against the Government, its agencies or instrumentalities, or to join the Government, its agencies or instrumentalities, as a codefendant in any action against the Contractor brought to determine the Contractor's liability or for any other purpose. (b) TYPES OF INSURANCE AND MINIMUM COVERAGE. The Contractor shall at its own expense, provide and maintain the following insurances during the entire performance of this contract. (1) Workmen's Compensation, including Longshoremen & Harbor Worker's Act coverage - Covering all agents, servants, borrowed servants, statutory employees of Contractor for all compensation and other benefits required by applicable state and federal law or by governmental authority on account of injury, death, sickness or disease - Statutory - no minimum. (2) Employers Liability - to cover both injury and death resulting from accident, sickness or disease - $ 1 million bodily injury by accident, each accident - $ 1 million bodily injury by disease each accident - $ 1 million bodily injury by disease in the aggregate. (3) Maritime Employers Liability (Jones Act) to cover both injury and death resulting from accident, sickness or disease - $ 1 million for each person per occurrence and $5 million in the aggregate. (4) Comprehensive General Liability to include coverage for (but not limited to) products and completed operations liability, property damage liability and contractual liability - $ 1 million combined single per occurrence limit for bodily injury and property damage and $ 1 million in the aggregate. (5) Ship Repairers Legal Liability - coverage to be provided under the standard London or American Institute forms or their equivalent $ 1 million per vessel, per occurrence or such other amount as may be requested. (c) All such insurance shall be subject to the approval of the Division of Marine Insurance and will contain thirty (30) calendar days advance notice of cancellation or of any non-renewal which is the option of the insurer, said notice to be provided to the U.S. Maritime Administration, Division of Marine Insurance MAR-710, 1200New Jersey Avenue SE, Washington, DC 20590. (d) FORM OF CONFIRMATION (1) The pollution insurance (if applicable) may be a separate policy or part of the Comprehensive General Liability policy, but the coverage must be specifically shown on the required confirmation of insurance. Excess liability and umbrella liability policies may be used in the excess of primary policies to meet the minimum limit requirements. The United States of America shall be an additional assured in the Ship Repairs Legal Liability policy, Comprehensive General Liability Policy and Pollution Policy. Such policies shall contain a clause statement that there is no recourse against the United States of America for payment of premium. All such insurance shall be subject to the approval of the Division of Marine Insurance and must contain thirty (30) calendar days advance notice of cancellation (without disclaimer) or of any non-renewal which is the option of the insurer, said notice to be provided to the U.S. Maritime Administration, Division of Marine Insurance MAR-710, 1200 New Jersey Avenue SE, Washington, DC 20590. (2) The Contractor shall have its insurance broker provide a detailed certificate of insurance, cover note or policy confirming the above required coverage. The confirmation shall name the Contractor and United States of America as assureds and confirm the types of coverage, policy forms, policy periods, deductibles (if any) and underwriters with their percentage of participation. The N.Y. Suable Clause or Service of Suit USA Clause must be confirmed for any Foreign underwriter placements. The policy amounts, terms and conditions, deductibles and underwriters shall at all times be satisfactory to the Maritime Administration. (e) The contractor shall insert the substance of this clause in subcontracts under this contract that require work on a Government installation. MCL.H-6 Standards of Employee Conduct The Contractor shall be responsible for maintaining satisfactory standards of employee competency, conduct, and integrity, and shall be responsible for taking such disciplinary action with respect to its employees as may be necessary. MCL.H-10 Supplemental Growth Requirements The labor rate offered in Section B under the Supplemental Repair Work CL1N shall be a yardwide composite labor rate and shall include all management, supervision, overhead, G&A, handling charges, freight and profit. The yardwide composite rate offered by the Contractor shall be binding during the entire period of this Contract for all supplemental work which cannot be accurately described at this time and is not included in other CLIN specifications. The Government may order up to 50 percent more hours than are currently estimated in the CLIN at the same labor rate provided therein. MCL.H-11 Disposition of Removed Equipment and Scrap Any ship's equipment, fuel, lube oil, supplies, stores, furniture, fixtures, salvage, scrap and other movable property, removed from the vessel shall be and become the property of the Government and any ship's equipment, fuel, supplies, lube oil, stores, furniture, fixtures, salvage, scrap and other movable property so removed shall be disposed of in such manner as the Contracting Officer may direct, provided such direction is given to the Contractor within sixty (60) days from the date of the completion of the work. During said sixty (60) calendar days period such ship's equipment, fuel, lube oil, supplies, stores, furniture, fixtures, salvage, scrap and other moveable property shall be stored and protected by the Contractor without charge to the Government. If within sixty (60) calendar days such direction is not given to the Contractor, it shall, after said sixty (60) calendar days, store and protect the same in the Contractor's facility or outside of the Contractor's facility, at the Contractor's election, for the additional period directed by the Government. Such direction shall be covered by a change order, and the increased contract price for such additional storage shall be determined as provided in the changes provisions of this contract. MCL.H-12 Maritime Liens, No Authority to Incur (a) The Contractor is an independent contractor and does not act as an agent for the Government, its agents, its vessels, servants, or employees. (b) The Contractor, its agents, servants, and employees, and all persons acting by, at the direction of, or on behalf of the Contractor (including, without limitation any subcontractors) have no right, power, or authority whatsoever to create, incur, or permit to be placed or imposed (i) any lien or (ii) any right in remedy of any kind, upon or against any vessel upon which work is being performed under this Agreement or against the United States of America or its agents, vessels, servants, or employees. This contractual provision governs notwithstanding any other provision of this contract. (c) The Contractor, on behalf of itself, its agents, servants, and employees, and all persons acting by, at the direction of, or on behalf of the Contractor (including, without limitation any subcontractors) hereby waives its right to any maritime lien as well as any right in remedy of any kind based upon a maritime lien theory, upon or against any vessel upon which work has been, is being, or will be performed under this contract or against the United States of America or its agents, servants, or employees, whether known or unknown. The foregoing clause shall not prevent the Contractor's rights to proceed on this contract under the Contract Disputes Act. (d) The Contractor shall pay when due all costs and expenses incident to the work performed by it or for its account. Neither the Contractor, nor its agents, servants, and employees, nor persons acting by, at the direction of, or on behalf of the Contractor (including, without limitation, any subcontractors) shall have the power to incur any lien of any kind maritime or otherwise. Such entities shall not (i) create, incur, suffer, or permit to be placed or imposed upon any vessel (or portion thereof), any maritime lien or other lien or encumbrance or charge in any way arising from any act or omission or (ii) incur or allow their subcontractors to incur any debts, obligations, or charges upon the credit of the vessel or against the United States of America or its agents, servants, or employees. (e) Although it is not intended that the Contractor shall have the power to incur such liens, the Contractor shall immediately discharge or cause to be discharged any lien or right in remedy of any kind, whether incurred by the Contractor or its subcontractors, other than in favor of the Maritime Administration, which at any time exists or arises in connection with the work done or materials furnished under this contract. (f) If any lien or right in remedy is not immediately discharged, MARAD may discharge or cause to be discharged such lien or right in remedy at the expense of the Contractor. MARAD shall have the right to recoup or setoff such funds from any monies owing to the Contractor from any other MARAD contract or any other Government contract. Should a question exist whether there is a valid lien or right in remedy, among other rights, MARAD shall have the right to retain such funds as security without interest. (g) From the start of work under this contract the Contractor shall cause a notice, reading as follows (or containing such other information as may be approved by MARAD), in plain type and of such size that the reading matter shall cover a space of at least 2 feet wide by 2 feet high in weather resistant paint to be placed and maintained by the gangway and shall read as follows: "NOTICE TO SUBCONTRACTORS, MATERIALMEN, AND LABORERS This vessel is owned by the United States of America, acting by and through the Maritime Administration. The Contractor, and all persons acting by, (prime contractor), at the direction of, or on behalf of the Contractor (including, without limitation, any subcontractors) have no right, power, or authority whatsoever to create, incur, or permit to be placed or imposed any lien or right in remedy of any kind upon any vessel upon which work is being performed under this Agreement. The Contractor, its agents, servants, and employees, have no authority, either express or implied, to pledge the credit of said vessel." (h) At the option of MARAD, the Contracting Officer may require that as a condition either for entry upon a vessel of the MARAD by any subcontractor or in order for any subcontractor to provide necessaries to a vessel of the MARAD, that such subcontractor shall on behalf of itself, its agents, subcontractors, servants, and employees, and all persons acting by, at the direction of, or on behalf of such subcontractor waive its right to any maritime lien as well as any right in remedy of any kind based upon a maritime lien theory, upon or against any vessel upon which work has been, is being, or will be performed under this contract or against the United States of America or its agents, servants, and employees, known or unknown. The foregoing clause shall not prevent such subcontractor's right, if any, to proceed under the Contract Disputes Act. (i) The foregoing clause shall not deprive MARAD of any of the rights or remedies which it has under the common law. Solicitation Provisions 52.212-1 Instructions to Offerors - Commercial Items. (JAN 2017) (a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code and small business size standard for this acquisition appear in Block 10 of the solicitation cover sheet ( SF 1449 ). However, the small business size standard for a concern which submits an offer in its own name, but which proposes to furnish an item which it did not itself manufacture, is 500 employees. (b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show— (1) The solicitation number; (2) The time specified in the solicitation for receipt of offers; (3) The name, address, and telephone number of the offeror; (4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary; (5) Terms of any express warranty; (6) Price and any discount terms; (7) “Remit to” address, if different than mailing address; (8) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-3 ( b) for those representations and certifications that the offeror shall complete electronically); (9) Acknowledgment of Solicitation Amendments; (10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and (11) If the offer is not submitted on th e SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration. (c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation. (d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender’s request and expense, unless they are destroyed during preaward testing. (e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions, including alternative line items (provided that the alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation), or alternative commercial items for satisfying the requirements of this solicitation. Each offer submitted will be evaluated separately. (f) Late submissions, modifications, revisions, and withdrawals of offers. (1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due. (2)(i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and— (A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or (B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government’s control prior to the time set for receipt of offers; or (C) If this solicitation is a request for proposals, it was the only proposal received. (ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted. (3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel. (4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume. (5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers. Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer. (g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror’s initial offer should contain the offeror’s best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received. (h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer. (i) Availability of requirements documents cited in the solicitation. (1)(i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to— GSA Federal Supply Service Specifications Section Suite 8100 470 East L’Enfant Plaza, SW Washington, DC 20407 Telephone (202) 619-8925 Facsimile (202) 619-8978. (ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (i)(1)(i) of this provision. Additional copies will be issued for a fee. (2) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites: (i) ASSIST ( https://assist.dla.mil/online/start/ ). (ii) Quick Search ( http://quicksearch.dla.mil/ ). (iii) ASSISTdocs.com ( http://assistdocs.com ). (3) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by— (i) Using the ASSIST Shopping Wizard ( https://assist.dla.mil/wizard/index.cfm ) ; (ii) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or (iii) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone (215) 697-2667/2179, Facsimile (215) 697-1462. (4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance. (j) Unique entity identifier. (Applies to all offers exceeding $3,500, and offers of $3,500 or less if the solicitation requires the Contractor to be registered in the System for Award Management (SAM) database.) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation “Unique Entity Identifier” followed by the unique entity identifier that identifies the Offeror’s name and address. The Offeror also shall enter its Electronic Funds Transfer (EFT) indicator, if applicable. The EFT indicator is a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the Offeror to establish additional SAM records for identifying alternative EFT accounts (see subpart 32.11 ) for the same entity. If the Offeror does not have a unique entity identifier, it should contact the entity designated a t www.sam.gov f or unique entity identifier establishment directly to obtain one. The Offeror should indicate that it is an offeror for a Government contract when contacting the entity designated at www.sam.gov for establishing the unique entity identifier. (k) System for Award Management. Unless exempted by an addendum to this solicitation, by submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance and through final payment of any contract resulting from this solicitation. If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror. Offerors may obtain information on registration and annual confirmation requirements via the SAM database accessed through https://www.acquisition.gov. (l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable: (1) The agency’s evaluation of the significant weak or deficient factors in the debriefed offeror’s offer. (2) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror. (3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection. (4) A summary of the rationale for award; (5) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror. (6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency. QUOTATION SUBMISSION INSTRUCTIONS: In addition to the referenced provision 52.212-1, Instructions to Offeror – Commercial Items, quoters shall provide the following information. 1. Offeror shall provide documentation to be evaluated in determining Technical Acceptability to include: a. Provide a technical approach narrative addressing how the individual work items will be accomplished. The narrative shall not exceed six (6) 8 ½ x 11 single sided typewritten pages using Times New Roman Font, 10 or 12 pitch. b. Provide a listing of key personnel who are expected to be utilized during the availability and their resumes. 2. To permit evaluation of Relevant Past Performance, Quoter shall provide: a. Provide a listing of boiler inspection, testing and repairs completed within the past 3 years involving vessels of similar characteristics to those of the T.S. KENNEDY or larger (i.e., MARAD Ready Reserve Force Vessels). Include with the listing contact information for the owner/operator of the vessel and/or the Contracting Officer for Public Vessels. b. The Contracting Officer may also use past performance information available in Government past performance databases. 3. Offeror shall include a price for each ITEM as well as a total contract price on the attached Quote Excel Spreadsheet, Attachment #2 (applies to base and optional items). 4. All signed SF-30, Amendment to Solicitation (if applicable) 5. With quote, please complete and submit the following FAR provision by checking the appropriate block: a. FAR 52.212-3 Offeror Representations and Certification – Commercial Items 6. Payment terms (i.e. Net 30) 7. Remittance address, Tax Identification Number, Dunn and Bradstreet number and Cage Code 8. Validity of quote (Please specify if the quote is valid for 30 days from solicitation response date) Responses to this solicitation are due no later than Friday, June 30, 2017 at 2:00 p.m. Eastern Standard Time for Norfolk, VA. LATE QUOTATIONS WILL NOT BE CONSIDERED FOR EVALUATION. Quotes may be emailed to monique.leake@dot.gov. Faxed quotes will not be accepted. PLEASE REFERENCE THE SOLICITATION NUMBER OF 6933A217Q00004. 52.212-2 Evaluation - Commercial Items. (OCT 2014) (a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers: 1. Price The total evaluated price will be the sum of quotes for all contract line items (applies to base and optional items). 2. Technical Acceptability (non-cost factor) Technical information submitted will be evaluated to determine if the quoter has acceptable technical capability for performing the requirements described in the solicitation. 3. Past Performance (non-cost factor) Past performance information will be evaluated to determine the offeror’s ability to perform the contract successfully and degree of performance risk associated with an offeror. The Contracting Officer may review information from references provided by the offeror as well as information available in Government past performance databases. BASIS FOR AWARD Award will be made on the basis of the lowest evaluated price of proposals meeting or exceeding the acceptability standards for non-cost factors. (b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s). (c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award. (End of provision) 52.212-3 Offeror Representations and Certifications-Commercial Items. (JAN 2017) The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) website located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision. (a) Definitions. As used in this provision— “Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. “Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. “Civil judgment” means– (1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction. (2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. “DOL Guidance” means the Department of Labor (DOL) Guidance entitled: “Guidance for Executive Order 13673, ‘Fair Pay and Safe Workplaces’”. The DOL Guidance was initially published in the Federal Register on August 25, 2016, and significant revisions will be published for public comment in the Federal Register. The DOL Guidance and subsequent versions can be obtained from www.dol.gov/fairpayandsafeworkplaces. “Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program. “Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are– (1) Department of Labor Wage and Hour Division (WHD) for– (i) The Fair Labor Standards Act; (ii) The Migrant and Seasonal Agricultural Worker Protection Act; (iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act; (iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act; (v) The Family and Medical Leave Act; and (vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors); (2) Department of Labor Occupational Safety and Health Administration (OSHA) for– (i) The Occupational Safety and Health Act of 1970; and (ii) OSHA-approved State Plans; (3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for– (i) Section 503 of the Rehabilitation Act of 1973; (ii) The Vietnam Era Veterans’ Readjustment Assistance Act of 1972 and the Vietnam Era Veterans’ Readjustment Assistance Act of 1974; and (iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity); (4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and (5) Equal Employment Opportunity Commission (EEOC) for– (i) Title VII of the Civil Rights Act of 1964; (ii) The Americans with Disabilities Act of 1990; (iii) The Age Discrimination in Employment Act of 1967; and (iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act). “Forced or indentured child labor” means all work or service— (6) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or (7) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties. “Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner. “Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees. “Inverted domestic corporation”, means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c). “Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters. “Labor laws” means the following labor laws and E.O.s: (1) The Fair Labor Standards Act. (2) The Occupational Safety and Health Act (OSHA) of 1970. (3) The Migrant and Seasonal Agricultural Worker Protection Act. (4) The National Labor Relations Act. (5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act. (6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act. (7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity). (8) Section 503 of the Rehabilitation Act of 1973. (9) The Vietnam Era Veterans’ Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974. (10) The Family and Medical Leave Act. (11) Title VII of the Civil Rights Act of 1964. (12) The Americans with Disabilities Act of 1990. (13) The Age Discrimination in Employment Act of 1967. (14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors). (15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html ). “Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of “labor laws”. “Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except— (1) PSC 5510, Lumber and Related Basic Wood Materials; (2) Product or Service Group (PSG) 87, Agricultural Supplies; (3) PSG 88, Live Animals; (4) PSG 89, Subsistence; (5) PSC 9410, Crude Grades of Plant Materials; (6) PSC 9430, Miscellaneous Crude Animal Products, Inedible; (7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products; (8) PSC 9610, Ores; (9) PSC 9620, Minerals, Natural and Synthetic; and (10) PSC 9630, Additive Metal Materials. “Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture. “Predecessor” means an entity that is replaced by a successor and includes any predecessors of the predecessor. “Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate— (1) Are conducted under contract directly and exclusively with the regional government of southern Sudan; (2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization; (3) Consist of providing goods or services to marginalized populations of Sudan; (4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization; (5) Consist of providing goods or services that are used only to promote health or education; or (6) Have been voluntarily suspended. “Sensitive technology”— (1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically— (i) To restrict the free flow of unbiased information in Iran; or (ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and (2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act ( 50 U.S.C. 1702(b)(3) ). “Service-disabled veteran-owned small business concern”— (1) Means a small business concern— (i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and (ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran. (2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16). “Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation. “Small disadvantaged business concern”, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that— (1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by— (i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and (ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and (2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition. “Subsidiary” means an entity in which more than 50 percent of the entity is owned— (1) Directly by a parent corporation; or (2) Through another subsidiary of a parent corporation. “Veteran-owned small business concern” means a small business concern— (1) Not less than 51 percent of which is owned by one or more veterans (as defined a t 38 U.S.C. 101(2) ) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and (2) The management and daily business operations of which are controlled by one or more veterans. “Successor” means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances. “Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women. “Women-owned small business concern” means a small business concern— (1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and (2) Whose management and daily business operations are controlled by one or more women. “Women-owned small business (WOSB) concern eligible under the WOSB Program” (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States. Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: “Administrative merits determination”, “Arbitral award or decision”, paragraph (2) of “Civil judgment”, “DOL Guidance”, “Enforcement agency”, “Labor compliance agreement”, “Labor laws”, and “Labor law decision”. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, GSA, DoD and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. (b)(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAM website. (2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through http://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications—Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201 ), except for paragraphs ______________. [Offeror to identify the applicable paragraphs at (c) through (t) of this provision that the offeror has completed for the purposes of this solicitation only, if any. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.] (c) Offerors must complete the following representations when the resulting contract will be performed in the United States or its outlying areas. Check all that apply. (1) Small business concern. The offeror represents as part of its offer that it □ is, □ is not a small business concern. (2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it □ is, □ is not a veteran-owned small business concern. (3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it □ is, □ is not a service-disabled veteran-owned small business concern. (4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, that it □ is, □ is not a small disadvantaged business concern as defined in 13 CFR 124.1002. (5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it □ is, □ is not a women-owned small business concern. (6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that— (i) It □ is,□ is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It □ is, □ is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: __________.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation. (7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that— (i) It □ is, □ is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It □ is, □ is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: __________.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation. Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold. (8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it □ is a women-owned business concern. (9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:____________________________________ (10) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that— (i) It □ is, □ is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and (ii) It □ is, □ is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: __________.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation. (d) Representations required to implement provisions of Executive Order 11246— (1) Previous contracts and compliance. The offeror represents that— (i) It □ has, □ has not participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation; and (ii) It □ has, □ has not filed all required compliance reports. (2) Affirmative Action Compliance. The offeror represents that— (i) It □ has developed and has on file, □ has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 cfr parts 60-1 and 60-2), or (ii) It □ has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor. (e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made. (f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American—Supplies, is included in this solicitation.) (1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.” The terms “commercially available off-the-shelf (COTS) item” “component,” “domestic end product,” “end product,” “foreign end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American—Supplies.” (2) Foreign End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. (g)(1) Buy American—Free Trade Agreements—Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American—Free Trade Agreements—Israeli Trade Act, is included in this solicitation.) (i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms “Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product,” “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” “Free Trade Agreement country,” “Free Trade Agreement country end product,” “Israeli end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements–Israeli Trade Act.” (ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”: Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) of this provision) as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act.” The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.” Other Foreign End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. (2) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate I. If Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”: Canadian End Products: Line Item No. _______________________________________ _______________________________________ _______________________________________ [List as necessary] (3) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate II. If Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”: Canadian or Israeli End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (4) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate III. If Alternate III to the clause at 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled “Buy American-Free Trade Agreements-Israeli Trade Act”: Free Trade Agreement Country End Products (Other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (5) Trade Agreements Certificate. (Applies only if the clause at FAR 52.225-5, Trade Agreements, is included in this solicitation.) (i) The offeror certifies that each end product, except those listed in paragraph (g)(5)(ii) of this provision, is a U.S.-made or designated country end product, as defined in the clause of this solicitation entitled “Trade Agreements.” (ii) The offeror shall list as other end products those end products that are not U.S.-made or designated country end products. Other End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (iii) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. For line items covered by the WTO GPA, the Government will evaluate offers of U.S.-made or designated country end products without regard to the restrictions of the Buy American statute. The Government will consider for award only offers of U.S.-made or designated country end products unless the Contracting Officer determines that there are no offers for such products or that the offers for such products are insufficient to fulfill the requirements of the solicitation. (h) Certification Regarding Responsibility Matters (Executive Order 12689). (Applies only if the contract value is expected to exceed the simplified acquisition threshold.) The offeror certifies, to the best of its knowledge and belief, that the offeror and/or any of its principals— (1) □ Are, □ are not presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency; (2) □ Have, □ have not, within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a Federal, state or local government contract or subcontract; violation of Federal or state antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property; (3) □ Are, □ are not presently indicted for, or otherwise criminally or civilly charged by a Government entity with, commission of any of these offenses enumerated in paragraph (h)(2) of this clause; and (4) □ Have, □ have not, within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied. (i) Taxes are considered delinquent if both of the following criteria apply: (A) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted. (B) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded. (ii) Examples. (A) The taxpayer has received a statutory notice of deficiency, under I.R.C. §6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights. (B) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. §6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights. (C) The taxpayer has entered into an installment agreement pursuant to I.R.C. §6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment. (D) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. §362 (the Bankruptcy Code). (i) Certification Regarding Knowledge of Child Labor for Listed End Products (Executive Order 13126). [The Contracting Officer must list in paragraph (i)(1) any end products being acquired under this solicitation that are included in the List of Products Requiring Contractor Certification as to Forced or Indentured Child Labor, unless excluded at.] (1) Listed end products. Listed End Product Listed Countries of Origin ___________________ ___________________ ___________________ ___________________ (2) Certification. [If the Contracting Officer has identified end products and countries of origin in paragraph (i)(1) of this provision, then the offeror must certify to either (i)(2)(i) or (i)(2)(ii) by checking the appropriate block.] □ (i) The offeror will not supply any end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product. □ (ii) The offeror may supply an end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product. The offeror certifies that it has made a good faith effort to determine whether forced or indentured child labor was used to mine, produce, or manufacture any such end product furnished under this contract. On the basis of those efforts, the offeror certifies that it is not aware of any such use of child labor. (j) Place of manufacture. (Does not apply unless the solicitation is predominantly for the acquisition of manufactured end products.) For statistical purposes only, the offeror shall indicate whether the place of manufacture of the end products it expects to provide in response to this solicitation is predominantly— (1) □ In the United States (Check this box if the total anticipated price of offered end products manufactured in the United States exceeds the total anticipated price of offered end products manufactured outside the United States); or (2) □ Outside the United States. (k) Certificates regarding exemptions from the application of the Service Contract Labor Standards (Certification by the offeror as to its compliance with respect to the contract also constitutes its certification as to compliance by its subcontractor if it subcontracts out the exempt services.) [The contracting officer is to check a box to indicate if paragraph (k)(1) or (k)(2) applies.] □ (1) Maintenance, calibration, or repair of certain equipment as described in FAR 22.1003-4 ( c)(1). The offeror □ does □ does not certify that— (i) The items of equipment to be serviced under this contract are used regularly for other than Governmental purposes and are sold or traded by the offeror (or subcontractor in the case of an exempt subcontract) in substantial quantities to the general public in the course of normal business operations; (ii) The services will be furnished at prices which are, or are based on, established catalog or market prices (see FAR 22.1003-4 ( c)(2)(ii)) for the maintenance, calibration, or repair of such equipment; and (iii) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract will be the same as that used for these employees and equivalent employees servicing the same equipment of commercial customers. □ (2) Certain services as described in FAR 22.1003-4 ( d)(1). The offeror □ does □ does not certify that— (i) The services under the contract are offered and sold regularly to non-Governmental customers, and are provided by the offeror (or subcontractor in the case of an exempt subcontract) to the general public in substantial quantities in the course of normal business operations; (ii) The contract services will be furnished at prices that are, or are based on, established catalog or market prices (see FAR 22.1003-4 ( d)(2)(iii)); (iii) Each service employee who will perform the services under the contract will spend only a small portion of his or her time (a monthly average of less than 20 percent of the available hours on an annualized basis, or less than 20 percent of available hours during the contract period if the contract period is less than a month) servicing the Government contract; and (iv) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract is the same as that used for these employees and equivalent employees servicing commercial customers. (3) If paragraph (k)(1) or (k)(2) of this clause applies— (i) If the offeror does not certify to the conditions in paragraph (k)(1) or (k)(2) and the Contracting Officer did not attach a Service Contract Labor Standards wage determination to the solicitation, the offeror shall notify the Contracting Officer as soon as possible; and (ii) The Contracting Officer may not make an award to the offeror if the offeror fails to execute the certification in paragraph (k)(1) or (k)(2) of this clause or to contact the Contracting Officer as required in paragraph (k)(3)(i) of this clause. (l) Taxpayer Identification Number (TIN) ( 26 U.S.C. 610 9, 31 U.S.C. 7701). (Not applicable if the offeror is required to provide this information to the SAM database to be eligible for award.) (1) All offerors must submit the information required in paragraphs (l)(3) through (l)(5) of this provision to comply with debt collection requirements of 31 U.S.C. 7701(c) and 3325(d), reporting requirements of 26 U.S.C. 6041, 6041A, and 6050M, and implementing regulations issued by the Internal Revenue Service (IRS). (2) The TIN may be used by the Government to collect and report on any delinquent amounts arising out of the offeror’s relationship with the Government ( 31 U.S.C. 7701(c)(3) ). If the resulting contract is subject to the payment reporting requirements described in FAR 4.904, the TIN provided hereunder may be matched with IRS records to verify the accuracy of the offeror’s TIN. (3) Taxpayer Identification Number (TIN). □ TIN: ________________________________. □ TIN has been applied for. □ TIN is not required because: □ Offeror is a nonresident alien, foreign corporation, or foreign partnership that does not have income effectively connected with the conduct of a trade or business in the United States and does not have an office or place of business or a fiscal paying agent in the United States; □ Offeror is an agency or instrumentality of a foreign government; □ Offeror is an agency or instrumentality of the Federal Government. (4) Type of organization. □ Sole proprietorship; □ Partnership; □ Corporate entity (not tax-exempt); □ Corporate entity (tax-exempt); □ Government entity (Federal, State, or local); □ Foreign government; □ International organization per 26 CFR 1.6049-4; □ Other ________________________________. (5) Common parent. □ Offeror is not owned or controlled by a common parent; □ Name and TIN of common parent: Name ________________________________. TIN _________________________________. (m) Restricted business operations in Sudan. By submission of its offer, the offeror certifies that the offeror does not conduct any restricted business operations in Sudan. (n) Prohibition on Contracting with Inverted Domestic Corporations. (1) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-2 ( b) applies or the requirement is waived in accordance with the procedures at 9.108-4. (2) Representation. The Offeror represents that— (i) It □ is, □ is not an inverted domestic corporation; and (ii) It □ is, □ is not a subsidiary of an inverted domestic corporation. (o) Prohibition on contracting with entities engaging in certain activities or transactions relating to Iran. (1) The offeror shall e-mail questions concerning sensitive technology to the Department of State at CISADA106@state.gov. (2) Representation and Certifications. Unless a waiver is granted or an exception applies as provided in paragraph (o)(3) of this provision, by submission of its offer, the offeror— (i) Represents, to the best of its knowledge and belief, that the offeror does not export any sensitive technology to the government of Iran or any entities or individuals owned or controlled by, or acting on behalf or at the direction of, the government of Iran; (ii) Certifies that the offeror, or any person owned or controlled by the offeror, does not engage in any activities for which sanctions may be imposed under section 5 of the Iran Sanctions Act; and (iii) Certifies that the offeror, and any person owned or controlled by the offeror, does not knowingly engage in any transaction that exceeds $3,500 with Iran’s Revolutionary Guard Corps or any of its officials, agents, or affiliates, the property and interests in property of which are blocked pursuant to the International Emergency Economic Powers Act (50 U.S.C. 1701 et seq.) (see OFAC’s Specially Designated Nationals and Blocked Persons List at http://www.treasury.gov/ofac/downloads/t11sdn.pdf ). (3) The representation and certification requirements of paragraph (o)(2) of this provision do not apply if— (i) This solicitation includes a trade agreements certification (e.g., 52.212-3 ( g) or a comparable agency provision); and (ii) The offeror has certified that all the offered products to be supplied are designated country end products. (p) Ownership or Control of Offeror. (Applies in all solicitations when there is a requirement to be registered in SAM or a requirement to have a unique entity identifier in the solicitation. (1) The Offeror represents that it □ has or □ does not have an immediate owner. If the Offeror has more than one immediate owner (such as a joint venture), then the Offeror shall respond to paragraph (2) and if applicable, paragraph (3) of this provision for each participant in the joint venture. (2) If the Offeror indicates “has” in paragraph (p)(1) of this provision, enter the following information: Immediate owner CAGE code: ____________________. Immediate owner legal name: _____________________. (Do not use a “doing business as” name) Is the immediate owner owned or controlled by another entity: □ Yes or □ No. (3) If the Offeror indicates “yes” in paragraph (p)(2) of this provision, indicating that the immediate owner is owned or controlled by another entity, then enter the following information: Highest-level owner CAGE code: __________________. Highest-level owner legal name: ___________________. (Do not use a “doing business as” name) (q) Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. (1) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, The Government will not enter into a contract with any corporation that— (i) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or (ii) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government. (2) The Offeror represents that— (i) It is □ is not □ a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and (ii) It is □ is not □ a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months. (r) Predecessor of Offeror. (Applies in all solicitations that include the provision at 52.204-16, Commercial and Government Entity Code Reporting.) (1) The Offeror represents that it □ is or □ is not a successor to a predecessor that held a Federal contract or grant within the last three years. (2) If the Offeror has indicated “is” in paragraph (r)(1) of this provision, enter the following information for all predecessors that held a Federal contract or grant within the last three years (if more than one predecessor, list in reverse chronological order): Predecessor CAGE code: ________ (or mark “Unknown”) Predecessor legal name: _________________________ (Do not use a “doing business as” name) (s) Representation regarding compliance with labor laws (Executive Order 13673). If the offeror is a joint venture that is not itself a separate legal entity, each concern participating in the joint venture shall separately comply with the requirements of this provision. (1)(i) For solicitations issued on or after October 25, 2016 through April 24, 2017: The Offeror □ does □ does not anticipate submitting an offer with an estimated contract value of greater than $50 million. (ii) For solicitations issued after April 24, 2017: The Offeror □ does □ does not anticipate submitting an offer with an estimated contract value of greater than $500,000. (2) If the Offeror checked “does” in paragraph (s)(1)(i) or (ii) of this provision, the Offeror represents to the best of the Offeror’s knowledge and belief [Offeror to check appropriate block]: □ (i) There has been no administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the offeror (see definitions in paragraph (a) of this section) during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter; or □ (ii) There has been an administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the Offeror during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter. (3)(i) If the box at paragraph (s)(2)(ii) of this provision is checked and the Contracting Officer has initiated a responsibility determination and has requested additional information, the Offeror shall provide– (A) The following information for each disclosed labor law decision in the System for Award Management (SAM) at www.sam.gov, unless the information is already current, accurate, and complete in SAM. This information will be publicly available in the Federal Awardee Performance and Integrity Information System (FAPIIS): (1) The labor law violated. (2) The case number, inspection number, charge number, docket number, or other unique identification number. (3) The date rendered. (4) The name of the court, arbitrator(s), agency, board, or commission that rendered the determination or decision; (B) The administrative merits determination, arbitral award or decision, or civil judgment document, to the Contracting Officer, if the Contracting Officer requires it; (C) In SAM, such additional information as the Offeror deems necessary to demonstrate its responsibility, including mitigating factors and remedial measures such as offeror actions taken to address the violations, labor compliance agreements, and other steps taken to achieve compliance with labor laws. Offerors may provide explanatory text and upload documents. This information will not be made public unless the contractor determines that it wants the information to be made public; and (D) The information in paragraphs (s)(3)(i)(A) and (s)(3)(i)(C) of this provision to the Contracting Officer, if the Offeror meets an exception to SAM registration (see FAR 4.1102 ( a)). (ii)(A) The Contracting Officer will consider all information provided under (s)(3)(i) of this provision as part of making a responsibility determination. (B) A representation that any labor law decision(s) were rendered against the Offeror will not necessarily result in withholding of an award under this solicitation. Failure of the Offeror to furnish a representation or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible. (C) The representation in paragraph (s)(2) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous representation, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation in accordance with the procedures set forth in FAR 12.403. (4) The Offeror shall provide immediate written notice to the Contracting Officer if at any time prior to contract award the Offeror learns that its representation at paragraph (s)(2) of this provision is no longer accurate. (5) The representation in paragraph (s)(2) of this provision will be public information in the Federal Awardee Performance and Integrity Information System (FAPIIS). Note to paragraph (s) : By a court order issued on October 24, 2016, this paragraph (s) is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, GSA, DoD and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. (t) Public Disclosure of Greenhouse Gas Emissions and Reduction Goals. Applies in all solicitations that require offerors to register in SAM ( 52.212-1 ( k)). (1) This representation shall be completed if the Offeror received $7.5 million or more in contract awards in the prior Federal fiscal year. The representation is optional if the Offeror received less than $7.5 million in Federal contract awards in the prior Federal fiscal year. (2) Representation. [Offeror to check applicable block(s) in paragraph (t)(2)(i) and (ii)]. (i) The Offeror (itself or through its immediate owner or highest-level owner) □ does, □ does not publicly disclose greenhouse gas emissions, i.e., makes available on a publicly accessible website the results of a greenhouse gas inventory, performed in accordance with an accounting standard with publicly available and consistently applied criteria, such as the Greenhouse Gas Protocol Corporate Standard. (ii) The Offeror (itself or through its immediate owner or highest-level owner) □ does, □ does not publicly disclose a quantitative greenhouse gas emissions reduction goal, i.e., make available on a publicly accessible website a target to reduce absolute emissions or emissions intensity by a specific quantity or percentage. (iii) A publicly accessible website includes the Offeror’s own website or a recognized, third-party greenhouse gas emissions reporting program. (3) If the Offeror checked “does” in paragraphs (t)(2)(i) or (t)(2)(ii) of this provision, respectively, the Offeror shall provide the publicly accessible website(s) where greenhouse gas emissions and/or reduction goals are reported:_________________. (u)(1) In accordance with section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions), Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with an entity that requires employees or subcontractors of such entity seeking to report waste, fraud, or abuse to sign internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting such waste, fraud, or abuse to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information. (2) The prohibition in paragraph (u)(1) of this provision does not contravene requirements applicable to Standard Form 312 (Classified Information Nondisclosure Agreement), Form 4414 (Sensitive Compartmented Information Nondisclosure Agreement), or any other form issued by a Federal department or agency governing the nondisclosure of classified information. (3) Representation. By submission of its offer, the Offeror represents that it will not require its employees or subcontractors to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting waste, fraud, or abuse related to the performance of a Government contract to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information (e.g., agency Office of the Inspector General). (End of provision) 52.233-2 Service of Protest. (SEP 2006) (a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from: Monique Leake Contracting Officer 7737 Hampton Blvd, Bldg 19, Suite 300 Norfolk, VA 23505 (b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO. (End of provision) MCL.L-2 Agency Protests (a) Prior to submission of an agency protest, all parties shall use their best efforts to resolve concerns raised by an interested party at the Contracting Officer level through open and frank discussions. At any time the Contracting Officer and Protestor are encouraged to employ the use of alternative dispute resolution techniques to resolve the protest. When this cannot be accomplished interested parties may submit an agency protest to the Contracting Officer set forth in the Service of Protest provision of this solicitation. (b) Protests based on alleged apparent improprieties in a solicitation shall be filed before bid opening or the closing date for receipt of proposals. In all other cases, protests shall be filed no later than 10 days after the basis of protest is known or should have been known, whichever is earlier. (c) Protests shall include the following information. Failure to substantially include any of the following may be grounds for dismissal of the protest. (i) Name, address, and fax and telephone numbers of the protester. (ii) Solicitation or contract number. (iii) Detailed statement of the legal and factual grounds for the protest, to include a description of resulting prejudice to the protester. (iv) Copies of relevant documents. (v) Request for a ruling by the agency. (vi) Statement as to the form of relief requested. (vii) All information establishing that the protester is an interested party for the purpose of filing a protest. (viii) All information establishing the timeliness of the protest. (d) Upon receipt and review of the protest to determine that adequate information is contained therein, the Contracting Officer will acknowledge receipt of the protest and inform the protester of the expected decision date. The Contracting Officer shall render a decision on the protest within 30 calendar days or notify the protestor of an extended decision date. (e) Upon receipt of the Contracting Officer's decision, the protestor may appeal the decision within 15 calendar days of decision receipt. The appeal will result in an independent review of the protest by the Head of the Contracting Activity, the Associate Administrator for Administration. The Head of the Contracting Activity will impartially review the protest as presented, taking into consideration all of the available information, and render a decision. To the extent permitted by law and regulation, the Head of the Contracting Activity shall request relevant information from both parties. The Head of the Contracting Activity will render a decision on the appeal within 15 calendar days of receipt. Agency appellate review of the Contracting Officer's decision on the protest will not extend GAO's timeliness requirements. Therefore, any subsequent protest to the GAO must be filed within 10 days of knowledge of initial adverse agency action (4 CFR 21.2(a)(3)). (f) Upon receipt of a protest, the Contracting Officer shall follow the procedures set forth in the FAR Subpart 33.103 (f) with regard to contract award and continued performance. ATTENTION: Minority, Women-Owned, and Disadvantaged Business Enterprises (DBEs). The Department of Transportation (DOT), Short-Term Lending Program (STLP) offers working capital financing in the form of lines of credit to finance accounts receivable for transportation related contracts. Maximum line of credit is $750,000 with interest at the prime rate, as published daily in the Wall Street Journal, plus 1.75 percent. For further information, call (800) 532-1169 or e-mail stlpinfo@dot.gov.
 

Web Link

FBO.gov Permalink
(https://www.fbo.gov/spg/DOT/MARAD/SAR/6933A217Q00004/listing.html)
 

Place of Performance

Address: T.S. KENNEDY, 101 ACADEMY DRIVE, BUZZARDS BAY, Massachusetts, 02532, United States

Zip Code: 02532
 

Record

SN04541595-W 20170614/170612235246-0c6a1c4c8c1d8f5440705d2787340734 (fbodaily.com)
 

Source

FedBizOpps Link to This Notice
(may not be valid after Archive Date)

---

| FSG Index  |  This Issue's Index  |  Today's FBO Daily Index Page |