MODIFICATION
72 -- Blackout Curtains
- Notice Date
- 8/30/2007
- Notice Type
- Modification
- NAICS
- 314121
— Curtain and Drapery Mills
- Contracting Office
- Department of the Air Force, Air Force Space Command, 90CONS, 7505 Marne Loop, F.E.Warren AFB, WY, 82005-2860, UNITED STATES
- ZIP Code
- 82005-2860
- Solicitation Number
- F1Y3DA7218A005
- Response Due
- 8/31/2007
- Archive Date
- 9/15/2007
- Point of Contact
- Doni Gourley, Contract Specialist, Phone 307 773 3323, Fax 307 773 4636,
- E-Mail Address
-
doni.gourley@warren.af.mil
- Small Business Set-Aside
- Total Small Business
- Description
- This is a combined Synopsis solicitation for commercial items prepared in accordance with the format in FAR 12 Sub Part 12.6 as supplemented with additional information included in this notice. This amendment clarifies the following: curtain color is indigo, traverse rod is split draw, drapery type is pinch pleat, no curtain or rod removal required, and both dorms will be available for curtain measurement and installation upon arrival of vender. The solicitation is set aside 100% for Small Business. The NAICS code is 314121. The Small Business Size Standard is 500 employees. Description of Services. The contractor shall provide all personnel, equipment, tools, materials and other items and services necessary to perform the installation of black-out draperies in dormitories on F. E Warren AFB WY. The contractor shall be fully responsible for compliance with all base, local, state, and Federal environmental/occupational safety laws, rules and regulations. The contractor shall follow life and safety codes, and take necessary actions to avoid conditions, which may be hazardous to the health and safety of base personnel. Basic Services. No rod and curtain removal is required. Services to be provided include, but are not limited to: Install new split draw traverse rods with sturdy pull cords to window wall with toggle bolts. Fasten new black-out pinch pleat curtains with sturdy hooks on rods using current industry standards. Repair any and all damages to room or building caused by contractor. Notify Unaccompanied Housing Management for all room access. A sample of all products used must be provided to the Contracting Officer for approval prior to any installation. If there is a change to any of the products used, another sample must be provided to the Contracting Officer prior to any installation of the substituted products. Required services to be completed within 90 days from award--both dorms will be available for curtain measurement and installation upon arrival of vender. Prior to installing draperies in any room, the contractor will re-measure the room to confirm measurements previously provided. If there is any difference between the measurements provided by the 90th CES/CEHD personnel and the contractor, the contractor must contact the 90th CES/CEHD prior to starting any work. If the contractor installs draperies prior to an agreement on any difference in measurements, the contractor is accepting the measurements provided by the 90th CES/CDM. DRAPERY INSTALLATION IN DORMITORIES: Dormitory 244 has approximately 70 windows that measure approximately 44 inches X 66 inches. Dormitory 248 has approximately 90 windows that measure approximately. 44.5 inches X 64.5 inches. All measurements are approximate and must be verified by the contractor. Drapery Specifications: Drapery material shall be: Fabricut or equal, Pinch Pleat, Pattern is: Macho, Color is indigo, 54 inches wide with 1-year warranty. Fiber-100% AVORA FR Polyester-Construction-Passes 30,000 Rubs Wyzenbeek Test method---Flame Retardant:-Inherently Flame Retardant---Testing Must Pass NFPA 701---Warranty-1 year. Black Out Lining: Black out lining material must be of white or off white in color and flame retardant. Product must be stitched to drapery material with acceptable industry standards and be waterproof. Support Equipment in Place. Government will ensure all furniture and appliances moved out of the way for contractor drapery installation. Contractor will be escorted to the dormitory room and allowed access to perform work. Security Passes. The contractor will be required to apply for vehicle passes through Pass and Registration (Bldg 232) and individual identification media through the 90th Contracting Squadron (Bldg 208). Upon completion or termination of the contract, or an individual?s employment on the project, the Contractor will retrieve the identification media issued above and surrender it to the Security Police, Pass and ID Section. All quotes will be inclusive of all costs. The following clauses will apply to this solicitation and will be incorporated into the award. The Government reserves the right to enter clauses into the award which are not in the solicitation with notice to the selected contractor. This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. The full text of a clause may be accessed electronically at this address: www.arnet.gov/far. Clauses include: 52.204-7 -- Central Contractor Registration. (July 2006), 52.212-1 -- Instructions to Offerors -- Commercial Items. (Sep 2006), 52.212-3 -- Offeror Representations and Certifications -- Commercial Items (Nov 2006), 52.212-4 -- Contract Terms and Conditions -- Commercial Items, (Feb 2007), 52.212-5 -- Contract Terms and Conditions Required to Implement Statutes or Executive Orders -- Commercial Items (Jun 2007), 252.204-7004 Alternate A Central Contractor Registration (NOV 2003), 252.212-7000 Offeror Representations and Certifications--Commercial Items (JUN 2005), 252.212-7001 Contract Terms and Conditions Required to Implement Statutes or Executive Orders Applicable to Defense Acquisitions of Commercial Items (Apr 2007). FAR Clause 52.252-2 Clauses Incorporated by Reference (Feb 1998). Clauses to be Incorporated by Full Text include 52.237-1 -- Site Visit (Apr 1984), 252.232-7003 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS (MAR 2007); 5352.223-9000 Elimination of Use of Class I Ozone Depleting Substances (ODS). (APR 2003). QUOTES ARE DUE NLT THAN 2:00 PM, MOUNTAIN DAYLIGHT TIME, 31 August 2007. You are encouraged to submit quotes electronically to doni.gourley@warren.af.mil . Quotes may also be submitted on letterhead and faxed to the attention of Donalda Gourley Contract Administrator @ 307-773-4636. All offerors must complete on-line registration at the following sites: The requirement calls for Contractors to be registered with the Central Contractor Registration (CCR) http://www.ccr.gov . Purchase orders cannot be awarded to companies that are not registered in CCR. Contractors must validate this information by registering at http://orca.bpn.gov. Quotes are being solicited for this requirement for planning purposes only. Should sufficient funding become available, the Government intends to award a Purchase Order. If funds do not become available by 30 September 2007 no award will be made. Points of Contact Ms. Donalda Gourley, Contract Specialist, Phone (307)-773-4911, FAX (307)-773-4636, email doni.gourley@warren.af.mil The Contracting Officer is Mr. WM Dutch Van Stockum, Phone (307)773-4789, Fax (307)-773-4636, email Dutch.Vanstockum@warren.af.mil. NOTE: THIS NOTICE WAS NOT POSTED TO FEDBIZOPPS ON THE DATE INDICATED IN THE NOTICE ITSELF (30-AUG-2007); HOWEVER, IT DID APPEAR IN THE FEDBIZOPPS FTP FEED ON THIS DATE. PLEASE CONTACT fbo.support@gsa.gov REGARDING THIS ISSUE.
- Web Link
-
Link to FedBizOpps document.
(http://www.fbo.gov/spg/USAF/AFSC/90CONS/F1Y3DA7218A005/listing.html)
- Place of Performance
- Address: 90th Contracting Squadron ATTN: Doni Gourley 7505 Marne Loop FE Warren AFB, WY 82005
- Zip Code: 82005
- Country: UNITED STATES
- Zip Code: 82005
- Record
- SN01391667-F 20070901/070830231151 (fbodaily.com)
- Source
-
FedBizOpps Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |