MODIFICATION
22 -- 120 Intermodal Container Wagons
- Notice Date
- 4/10/2004
- Notice Type
- Modification
- NAICS
- 339999
— All Other Miscellaneous Manufacturing
- Contracting Office
- Other Defense Agencies, Coalition Provisional Authority, Republican Presidential Compound, Republican Presidential Compound APO, Baghdad, Iraq, AE, 09335
- ZIP Code
- 09335
- Solicitation Number
- W914NS-04-Q-0165
- Response Due
- 4/25/2004
- Point of Contact
- Mario Troncoso, Contracting Officer, Phone 703-343-9225, Fax 703-343-9227,
- E-Mail Address
-
troncosom@orha.centcom.mil
- Description
- THE PURPOSE OF THIS AMENDMENT TO W914NS-04-Q-0165 IS TO CLARIFY THE TERMS OF DELIVERY, THE INFORMATION PROVIDED ON INSTRUCTIONS TO OFFERORS AND PROPOSAL EVALUATION. Desired delivery date for contract line item 0001 is 180 days after receipt of order. Contract line item 0002 is to begin the day of acceptance for each Intermodal Container Wagon. Contract line item 0003 is to begin 30 days after acceptance of the last Intermodal Container Wagon. Delivery destination can be either the custom’s yard at the rail station in Rabiya, Iraq or the custom’s receiving yard at the Port of Umm Qsar; N30.03219 E047.94332, Delivery Duty Unpaid, Cost, Insurance & Freight (DDU/CIF). SECTION L – INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS OR RESPONDENTS The Government intends to award only one contract. Offers must be submitted via paperless electronic media. You must submit your electronic offer, and any supplemental information, to cpa_contracting_acti@orha.centcom.mil no later than the date and time specified in this combined synopsis / solicitation. The subject line must contain the solicitation number. You may use multiple e-mail messages for each offer, however, you must annotate the subject lines as described above for each message, and number, (e. g. ,1 of 3, 2 of 3, 3 of 3) as appropriate. 52.212-1 Instructions to Offerors -- Commercial Items (Jan 2004) (a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code and small business size standard for this acquisition appear in Block 10 of the solicitation cover sheet (SF 1449). However, the small business size standard for a concern which submits an offer in its own name, but which proposes to furnish an item which it did not itself manufacture, is 500 employees. (b) Submission of offers. Submit offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show -- (1) The solicitation number; (2) The time specified in the solicitation for receipt of offers; (3) The name, e-mail address, postal address, and telephone number of the offeror; (4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. Offeror’s technical proposal (including delivery terms) shall be no longer than three pages of text. In addition, the Offeror’s technical proposal may also included one brochure or three pages containing pictures of the proposed ICW. The type characters no smaller that 10 pitch. No attachments are allowed. Only the front of a page shall be used. A page that has material on back and front will count as two pages. The contracting officer may determine proposals that deviate from these type-size and page limitations as non-responsive. (5) Terms of any express warranty; (6) Price and any discount terms. Offeror’s price proposal shall be no longer than three pages of text. The type characters no smaller that 10 pitch. No attachments are allowed. Only the front of a page shall be used. A page that has material on back and front will count as two pages. The contracting officer may determine proposals that deviate from these type-size and page limitations as non-responsive. (7) “Remit to” address, if different than mailing address; (8) A completed copy of the representations and certifications at FAR 52.212-3; (9) Acknowledgment of Solicitation Amendments; (10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the past 3 years, for the same or similar items and other references. The Offeror will provide no more than two pages of past performance information. Use type characters no smaller that 10 pitch. Each instance of relevant past performance shall include the contract number and / or delivery order number, contract type, contract value, whether competitive or sole source, description of work, and customer point of contact including e-mail address and telephone number; and (11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration. (12) Contractor MUST propose their price for each CLIN. (c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 60 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation. (d) Product samples. None are required (e) Multiple offers. Offerors are permitted to submit only one offer to this requirement. (f) Late submissions, modifications, revisions, and withdrawals of offers. (1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 5:00 p.m., local time, for the designated Government office on the date that offers or revisions are due. (2) (i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and— (A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or (B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government’s control prior to the time set for receipt of offers; or (C) If this solicitation is a request for proposals, it was the only proposal received. (ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted. (3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel. (4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume. (5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers. Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer. (g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror’s initial offer should contain the offeror’s best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received. (h) Multiple awards. The Government intends to make only one award. (i) Standards. Non-government standards must be obtained from the organization responsible for their preparation, publication or maintenance. (j) Data Universal Numbering System (DUNS) Number. (Applies to offers exceeding $25,000, and offers of $25,000 or less if the solicitation requires the Contractor to be registered in the Central Contractor Registration (CCR) database. The offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation “DUNS” or “DUNS+4” followed by the DUNS or DUNS+4 number that identifies the offeror’s name and address. The DUNS+4 is the DUNS number plus a 4-character suffix that may be assigned at the discretion of the offeror to establish additional CCR records for identifying alternative Electronic Funds Transfer (EFT) accounts (see FAR Subpart 32.11) for the same parent concern. If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one. An offeror within the United States may contact Dun and Bradstreet by calling 1-866-705-5711 or via the Internet at http://www.dnb.com. An offeror located outside the United States must contact the local Dun and Bradstreet office for DUNS number. (k) Central Contractor Registration. Prospective awardee shall be registered in the CCR database prior to award, during performance and through final payment of any contract resulting from this solicitation. If the Offeror does not become registered in the CCR database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror. Offerors may obtain information on registration and annual confirmation requirements via the Internet at http://www.ccr.gov or by calling 1-888-227-2423 or 269-961-5757. SECTION M – EVALUATION FACTORS FOR AWARD 52.212-2 -- Evaluation -- Commercial Items (Jan 1999) (a) This acquisition will utilize the Technically Acceptable-Performance/Price Tradeoff (TA-PPT) source selection procedure to make an integrated assessment for a best value award decision. A decision on the technical acceptability of each offeror’s proposal will be made. For those offerors who are determined to be technically acceptable, tradeoffs will be made between past performance and price, with past performance being considered equal to price. While the Government will strive for maximum objectivity, the tradeoff process, by its nature, is subjective; therefore, professional judgment is implicit throughout the selection process. Award will be made to the responsible offeror whose proposal conforms to all solicitation requirements, such as required delivery dates, terms and conditions, representations and certifications, and technical requirements, in addition to those included in paragraph (b)(1) below. (b) The TA-PPT evaluation process will be accomplished as follows: (1) Technical. Each offeror’s technical proposal, who meets the government’s required delivery dates, will be evaluated to determine if the offeror provides a sound, compliant approach to meeting the government’s minimum requirements as described in the Schedule of Supplies. Offeror’s proposals meeting the government’s minimum requirements will determined to be technically “acceptable”. (2) Performance. For technically acceptable proposals, the past performance assessment will assess the confidence in the offeror’s ability (which includes, if applicable, the extent of its critical subcontractors’ or teaming partners’ involvement) to successfully accomplish the proposed effort based on the offeror’s demonstrated present and past work record. The Government will evaluate the offeror’s demonstrated record of contract compliance in supplying products and services that meet users’ needs including cost and schedule. The currency and relevancy of the information, the source of the information, context of the data and general trends in the contractor’s performance will be considered. The Government will perform an independent determination of relevancy of the data provided or obtained. A relevancy determination of the offeror’s present/past performance (which includes, if applicable, the extent of its critical subcontractors’ or teaming partners’ involvement) will be made. The Government is not bound by the offeror’s opinion of relevancy. The Government may consider an offeror’s contracts in the aggregate in determining relevancy, should the offeror’s present and past performance lend itself to this approach. For example, an offeror’s work experience on three contracts may, by definition, represent only a semi-relevant effort when each contract is considered as a stand-alone effort. However, when these contracts are performed concurrently (in part or in whole) and are assessed in the aggregate, the work may more accurately reflect a very relevant effort. The following relevancy criteria apply: • VERY RELEVANT: Present/past performance programs involved the magnitude of effort and complexities which are essentially what this solicitation requires. • RELEVANT: Present/past performance programs involved less magnitude of effort and complexities, including most of what this solicitation requires. • SEMI-RELEVANT: Present/past performance programs involved much less magnitude of effort and complexities, including some of what this solicitation requires. • NOT RELEVANT: Did not involve any significant aspects of above. In assessing present and past performance, the Government will employ several approaches, including, but not limited to: (i). Information utilized may be obtained from the references listed in the proposal, as well as from other sources known to the Government. Data from previous source selections may be used if the data is recent and relevant. Evaluation of present and past performance will include consideration of overall customer satisfaction and conclusions of informed judgment. (ii). Offerors may be given an opportunity to address adverse past performance information if the offeror has not had a previous opportunity to respond to the information. Recent contracts will be examined to ensure that corrective measures have been implemented. The confidence assessment will consider issues including, but not limited to, the number and severity of the problems, the appropriateness and/or effectiveness of any corrective actions taken (not just planned or promised), and the offeror’s overall work record. Prompt corrective action in isolated instances may not outweigh overall negative trends. (iii). Past performance information will also be considered regarding any critical subcontractors and key personnel. If an offeror, or the proposed key employees of the offeror, do not have a past performance history deemed relevant to this solicitation, the offeror will receive a neutral confidence rating. The neutral confidence rating will be considered in the overall assessment for a best value decision. (iv) An overall confidence assessment rating will be made. The following confidence assessment ratings apply: Rating Definition Blue Based on the offerors record of performance there is exceptional/high confidence that they will perform successfully on this contract. Green Based on the offerors record of performance there is very good/significant confidence that they will perform successfully on this contract. Yellow Based on the offeror’s record of performance there is satisfactory/confidence that they will perform successfully on this contract. Grey Based on the offeror’s record of performance there is neutral/unknown confidence that they will perform successfully on this contract. Black Based on the offeror’s record of performance there is marginal/little confidence that they will perform successfully on this contract. Red Based on the offerors record of performance there is unsatisfactory/no confidence that they will perform successfully on this contract. (3) Price. (a) IAW FAR Part 15.305 (a)(1) Cost or Price Evaluation, this competitive procurement will establish the basis for price reasonableness. (b) Total evaluated price, for award purposes, will be based upon the total price proposed (b) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award. (End of Provision) For further information call Charles T. Clements at 703-343-9218 or e-mail at clementsc@orha.centcom.mil NOTE: THIS NOTICE MAY HAVE POSTED ON WWW.FEDBIZOPPS.GOV ON THE DATE INDICATED IN THE NOTICE ITSELF (10-APR-2004). IT ACTUALLY APPEARED OR REAPPEARED ON THE FEDBIZOPPS SYSTEM ON 25-MAY-2004, BUT REAPPEARED IN THE FTP FEED FOR THIS POSTING DATE. PLEASE CONTACT fbo.support@gsa.gov REGARDING THIS ISSUE.
- Web Link
-
Link to FedBizOpps document.
(http://www.eps.gov/spg/ODA/CPAIRAQ/APOAE/W914NS-04-Q-0165/listing.html)
- Place of Performance
- Address: Either the Port of Umm Qsar, Iraq or Rabiya, Iraq.
- Record
- SN00592616-F 20040527/040525213953 (fbodaily.com)
- Source
-
FedBizOpps.gov Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |